595006-2024 - Competition Competition Finland: Electrical installation work Overhead transmission line projects B-Qualification 2024 Finland, Anywhere in the given country Buyer Buyer: Fingrid Oyj Email: toimittajarekisteri@fingrid.fi Finland, Helsinki-Uusimaa (FI1B1), Helsinki LOT-0000: Overhead transmission line projects B-Qualification 2024 Electrical installation work Finland, Anywhere in the given country Start date: 20/09/2024 Duration end date: 31/10/2026 595006-2024 - Competition Finland – Electrical installation work – Overhead transmission line projects B-Qualification 2024 OJ S 193/2024 03/10/2024 Notice on the existence of a qualification system Works 1. Buyer 1.1. Buyer Official name: Fingrid Oyj Email: toimittajarekisteri@fingrid.fi Activity of the contracting entity: Electricity-related activities 2. Procedure 2.1. Procedure Title: Overhead transmission line projects B-Qualification 2024 Description: Fingrid's overhead transmission line projects B-Qualification 2024. Procedure identifier: 4753f15f-030a-4810-bf22-d7faa8491935 Internal identifier: 526952 2.1.1. Purpose Main nature of the contract: Works Main classification (cpv): 45310000 Electrical installation work 2.1.2. Place of performance Country: Finland Anywhere in the given country 2.1.4. General information Legal basis: Directive 2014/25/EU 2.1.6. Grounds for exclusion Analogous situation like bankruptcy under national law: The economic operator is in any analogous situation like bankruptcy arising from a similar procedure under national laws and regulations. Bankruptcy: The economic operator is bankrupt. Corruption: The economic operator itself or any person who is a member of its administrative, management or supervisory body or has powers of representation, decision or control therein has been the subject of a conviction by final judgment for corruption, by a conviction rendered at the most five years ago or in which an exclusion period set out directly in the conviction continues to be applicable. Arrangement with creditors: The economic operator is in arrangement with creditors. Participation in a criminal organisation: The economic operator itself or any person who is a member of its administrative, management or supervisory body or has powers of representation, decision or control therein has been the subject of a conviction by final judgment for participation in a criminal organisation, by a conviction rendered at the most five years ago or in which an exclusion period set out directly in the conviction continues to be applicable. Agreements with other economic operators aimed at distorting competition: The economic operator has entered into agreements with other economic operators aimed at distorting competition. Breaching of obligations in the fields of environmental law: The economic operator has breached its obligations in the field of environmental law. Money laundering or terrorist financing: The economic operator itself or any person who is a member of its administrative, management or supervisory body or has powers of representation, decision or control therein has been the subject of a conviction by final judgment for money laundering or terrorist financing, by a conviction rendered at the most five years ago or in which an exclusion period set out directly in the conviction continues to be applicable. Fraud: The economic operator itself or any person who is a member of its administrative, management or supervisory body or has powers of representation, decision or control therein has been the subject of a conviction by final judgment for fraud, by a conviction rendered at the most five years ago or in which an exclusion period set out directly in the conviction continues to be applicable. Child labour and other forms of trafficking in human beings: The economic operator itself or any person who is a member of its administrative, management or supervisory body or has powers of representation, decision or control therein has been the subject of a conviction by final judgment for child labour and other forms of trafficking in human beings, by a conviction rendered at the most five years ago or in which an exclusion period set out directly in the conviction continues to be applicable. Insolvency: The economic operator is the subject of insolvency or winding-up. Breaching of obligations in the fields of labour law: The economic operator has breached its obligations in the field of labour law. Assets being administered by liquidator: The assets of the economic operator are being administered by a liquidator or by the court. Guilty of misrepresentation, withheld information, unable to provide required documents and obtained confidential information of this procedure: The economic operator can confirm that: a) It has been guilty of serious misrepresentation in supplying the information required for the verification of the absence of grounds for exclusion or the fulfilment of the selection criteria, b) It has withheld such information, c) It has not been able, without delay, to submit the supporting documents required by a contracting authority or contracting entity, and d) It has undertaken to unduly influence the decision making process of the contracting authority or contracting entity, to obtain confidential information that may confer upon it undue advantages in the procurement procedure or to negligently provide misleading information that may have a material influence on decisions concerning exclusion, selection or award. Purely national exclusion grounds: Any person who is a member of the economic operator’s administrative, management or supervisory body or has powers of representation, decision or control therein has been the subject of a conviction by final judgment for work safety offence, working hours offence, work discrimination, extortionate work discrimination, violation of the right to organise or unauthorised use of foreign labour. Conflict of interest due to its participation in the procurement procedure: The economic operator is aware of any conflict of interest, as indicated in national law, the relevant notice or the procurement documents due to its participation in the procurement procedure. Direct or indirect involvement in the preparation of this procurement procedure: The economic operator or an undertaking related to it has advised the contracting authority or contracting entity or otherwise been involved in the preparation of the procurement procedure. Guilty of grave professional misconduct: The economic operator is guilty of grave professional misconduct. Early termination, damages or other comparable sanctions: The economic operator has experienced that a prior public contract, a prior contract with a contracting entity or a prior concession contract was terminated early, or that damages or other comparable sanctions were imposed in connection with that prior contract. Breaching of obligations in the fields of social law: The economic operator has breached its obligations in the field of social law. Payment of social security contributions: The economic operator has breached its obligations relating to the payment social security contributions, both in the country in which it is established and in Member State of the contracting authority or contracting entity if other than the country of establishment. Business activities are suspended: The business activities of the economic operator are suspended. Payment of taxes: The economic operator has breached its obligations relating to the payment of taxes, both in the country in which it is established and in Member State of the contracting authority or contracting entity if other than the country of establishment. Terrorist offences or offences linked to terrorist activities: The economic operator itself or any person who is a member of its administrative, management or supervisory body or has powers of representation, decision or control therein has been the subject of a conviction by final judgment for terrorist offences or offences linked to terrorist activities, by a conviction rendered at the most five years ago or in which an exclusion period set out directly in the conviction continues to be applicable. 5. Lot 5.1. Lot: LOT-0000 Title: Overhead transmission line projects B-Qualification 2024 Description: Fingrid's overhead transmission line projects B-Qualification 2024. Internal identifier: 759250 5.1.1. Purpose Main nature of the contract: Works Main classification (cpv): 45310000 Electrical installation work 5.1.2. Place of performance Country: Finland Anywhere in the given country 5.1.3. Estimated duration Start date: 20/09/2024 Duration end date: 31/10/2026 5.1.4. Renewal Maximum renewals: 0 5.1.6. General information Reserved participation: Participation is not reserved. The procurement is covered by the Government Procurement Agreement (GPA): no This procurement is also suitable for small and medium-sized enterprises (SMEs) 5.1.7. Strategic procurement Social objective promoted: Human rights due diligence in global supply chains Social objective promoted: Fair working conditions 5.1.9. Selection criteria Criterion: Type: Economic and financial standing Use of this criterion: Used Criterion: Type: Suitability to pursue the professional activity Use of this criterion: Not used Criterion: Type: Technical and professional ability Use of this criterion: Used 5.1.10. Award criteria Criterion: Type: Price 5.1.11. Procurement documents Deadline for requesting additional information: 30/10/2026 22:00:00 (UTC) Address of the procurement documents: https://tarjouspalvelu.fi/fingrid?id=526952&tpk=a2bf5464-0902-42f0-98b6-8636c04a53d0 5.1.12. Terms of procurement Terms of submission: Electronic submission: Required Address for submission: https://tarjouspalvelu.fi/fingrid?id=526952&tpk=a2bf5464-0902-42f0-98b6-8636c04a53d0 Languages in which tenders or requests to participate may be submitted: English 5.1.16. Further information, mediation and review Review organisation: Markkinaoikeus Organisation providing additional information about the procurement procedure: Fingrid Oyj TED eSender: Hansel Oy (Hilma) 8. Organisations 8.1. ORG-0001 Official name: Fingrid Oyj Registration number: 1072894-3 Postal address: Läkkisepäntie 21 Town: Helsinki Postcode: 00620 Country subdivision (NUTS): Helsinki-Uusimaa (FI1B1) Country: Finland Contact point: Keijo Välimaa Email: toimittajarekisteri@fingrid.fi Telephone: +358 303955000 Internet address: http://www.fingrid.fi Roles of this organisation: Buyer Organisation providing additional information about the procurement procedure 8.1. ORG-0002 Official name: Markkinaoikeus Registration number: 3006157-6 Postal address: Radanrakentajantie 5 Town: Helsinki Postcode: 00520 Country subdivision (NUTS): Helsinki-Uusimaa (FI1B1) Country: Finland Email: markkinaoikeus@oikeus.fi Telephone: +358 295643300 Internet address: http://www.oikeus.fi/markkinaoikeus Roles of this organisation: Review organisation 8.1. ORG-0003 Official name: Hansel Oy (Hilma) Registration number: FI09880841 Postal address: Mannerheiminaukio 1a Town: Helsinki Postcode: 00100 Country subdivision (NUTS): Helsinki-Uusimaa (FI1B1) Country: Finland Contact point: eSender Email: tekninen@hankintailmoitukset.fi Telephone: 029 55 636 30 Internet address: http://hankintailmoitukset.fi Roles of this organisation: TED eSender 11. Notice information 11.1. Notice information Notice identifier/version: 9616f19b-0af5-471c-a39d-a2bb22c63f0d - 01 Form type: Competition Notice type: Notice on the existence of a qualification system Notice subtype: 15 Notice dispatch date: 01/10/2024 12:07:28 (UTC) Notice dispatch date (eSender): 02/10/2024 07:53:00 (UTC) Languages in which this notice is officially available: English 11.2. Publication information Notice publication number: 595006-2024 OJ S issue number: 193/2024 Publication date: 03/10/2024 Czech document download: https://ted.europa.eu/cs/notice/595006-2024/pdf Danish document download: https://ted.europa.eu/da/notice/595006-2024/pdf German document download: https://ted.europa.eu/de/notice/595006-2024/pdf Greek document download: https://ted.europa.eu/el/notice/595006-2024/pdf Spanish document download: https://ted.europa.eu/es/notice/595006-2024/pdf English document download: https://ted.europa.eu/en/notice/595006-2024/pdf Estonian document download: https://ted.europa.eu/et/notice/595006-2024/pdf Finnish document download: https://ted.europa.eu/fi/notice/595006-2024/pdf French document download: https://ted.europa.eu/fr/notice/595006-2024/pdf Irish document download: https://ted.europa.eu/ga/notice/595006-2024/pdf Croatian document download: https://ted.europa.eu/hr/notice/595006-2024/pdf Hungarian document download: https://ted.europa.eu/hu/notice/595006-2024/pdf Italian document download: https://ted.europa.eu/it/notice/595006-2024/pdf Lithuanian document download: https://ted.europa.eu/lt/notice/595006-2024/pdf Latvian document download: https://ted.europa.eu/lv/notice/595006-2024/pdf Maltese document download: https://ted.europa.eu/mt/notice/595006-2024/pdf Dutch document download: https://ted.europa.eu/nl/notice/595006-2024/pdf Polska document download: https://ted.europa.eu/pl/notice/595006-2024/pdf Portuguese document download: https://ted.europa.eu/pt/notice/595006-2024/pdf Romanian document download: https://ted.europa.eu/ro/notice/595006-2024/pdf Slovak document download: https://ted.europa.eu/sk/notice/595006-2024/pdf Slovenian document download: https://ted.europa.eu/sl/notice/595006-2024/pdf Swedish document download: https://ted.europa.eu/sv/notice/595006-2024/pdf Bulgarian document download: https://ted.europa.eu/bg/notice/595006-2024/pdf